首页 > 演讲致辞 > 会议致辞 / 正文

FIDIC设计采购施工(EPC)合同条件(中英文对照版)_文档

2021-03-06 11:16:19 ℃

　CONTENTS

　1 General Provisions 一般规定

　1.1 Definitions 定义

　1.2 Interpretation 解释

　1.3 Communications 通信交流

　1.4 Law and Language 法律和语言

　1.5 Priority of Document 文件优先次序

　1.6 Contract Agreement 合同协议书

　1.7 Assignment 权益转让

　1.8 Care and Supply of Document 文件的照管和提供

　1.9 Confidentiality 保密性

　1.10 Employer’s Use of Contractor’s Documents 雇主使用承包商文件

　1.11 Contractor’s Use of Employer’s Documents 承包商使用雇主文件

　1.12 Confidential Details 保密事项

　1.13 Compliance with Laws 遵守法律

　1.14 Joint and Several Liability 共同的和各自的责任

　2 The Employer 雇主

　2.1 Right of Access to the Site 现场进入权

　2.2 Permits, Licences or Approves 许可、执照或批准

　2.3 Employer’s personnel 雇主人员

　2.4 Employer’s Financial Arrangements 雇主的资金安排

　2.5 Employer’s Claims 雇主的索赔

　3 The Employer’s Administration 雇主的管理

　3.1 The Employer’s Representative 雇主代表

　3.2 The Employer’s personnel 其他雇主人员

　3.3 Delegated Persons 受托人员

　3.4 Instructions 指示

　3.5 Determinations 确定

　4 The Contractor 承包商

　4.1 The Contractor’s General Obligations 承包商的一般义务

　4.2 Performance security 履约担保

　4.3 Contractor’s Representative 承包商代表

　4.4 Subcontractors 分包商

　4.5 Nominated Subcontractors 指定的分包商

　4.6 Co-operation 合作

　4.7 Setting out 放线

　4.8 Safety procedures 安全程序

　4.9 Quality Assurance 质量保证

　4.10 Site Data 现场数据

　4.11 Sufficiency of the Contract Price 合同价格

　4.12 Unforeseeable Difficulties 不可预见的困难

　4.13 Rights of way and Facilities 道路通行权于设施

　4.14 Avoidance of Interference 避免干扰

　 4.15 Access Route 进场通路

　 4.16 Transport of Goods 货物运输

　 4.17 Contractor’s Equipment 承包商设备

　 4.18 Protection of the Environment 环境保护

　 4.19 Electricity, Water and Gas 电、水和燃气

　 4.20 Employer’s Equipment and Free-Issue Material 雇主设备和免费供应的材料

　 4.21 Progress Reports 进度报告

　 4.22 Security of the Site 现场保安

　 4.23 Contractor’s Operations on Site 承包商的现场作业

　 4.24 Fossils 化石

　 5 Design 设计

　 5.1 General Design Obligations 设计义务一般要求

　 5.2 Contractor’s Documents 承包商文件

　 5.3 Contractor’s Undertaking 承包商的承诺

　 5.4 Technical Standards and Regulations 技术标准和法规

　 5.5 Training 培训

　 5.6 As-Built Documents 竣工文件

　 5.7 Operation and Maintenance Manuals 操作和维修手册

　 5.8 Design Error 设计错误

　 6 Staff and Labour 员工

　 6.1 Engagement of Staff and Labour 员工的雇用

　 6.2 Rates of Wages and Conditions of Labour 工资标准和劳动条件

　 6.3 Persons in the Service of Employer 为雇主服务的人员

　 6.4 Labour Laws 劳动法

　 6.5 Working Hours 工作时间

　 6.6 Facilities for Staff and Labour 为员工提供设施

　 6.7 Health and Safety 健康和安全

　 6.8 Contractor’s Superintendence 承包商的监督

　 6.9 Contractor’s Personnel 承包商人员

　 6.10 Records of contractor’s Personnel and Equipment 承包商人员和设备的记录

　 6.11 Disorderly Conduct 无序行为

　 7 Plant, Materials and Workmanship 生产设备、材料和工艺

　 7.1 Manner of Execution 实施方法

　 7.2 Samples 样品

　 7.3 Inspection 检验

　 7.4 Testing 试验

　 7.5 Rejection 拒收

　7.6 Remedial Work 修补工作

　 7.7 Ownership of Plant and Materials 生产设备和材料的所有权

　 7.8 Royalties 土地(矿区)使用费

　 8 Commencement,Delays and Suspension 开工、延误和暂停

　 8.1 Commencement of Works 工程的开工

　8.2 Time for Completion 竣工时间

　 8.3 Programme 进度计划

　 8.4 Extension of Time for Completion 竣工时间延长

　 8.5 Delays Caused by Authorities 当局造成的延误

　 8.6 Rate of Progress 工程进度

　 8.7 Delay Damages 误期损害赔偿费

　 8.8 Suspension of Work 暂时停工

　 8.9 Consequences of Suspension 暂停的后果

　 8.10 Payment for Plant and Materials in Event of Suspension 暂停时对生产设备和材料的付款

　8.11 Prolonged Suspension 托长的暂停

　 8.12 Resumption of Work 复工

　 9 Tests on Completion 竣工试验

　 9.1 Contractor’s Obligations 承包商的义务

　 9.2 Delayed Tests 延误的试验

　 9.3 Retesting 重新试验

　 9.4 Failure to Pass Tests on Completion 未能通过竣工试验

　 10 Employer’s Taking Over 雇主的接收

　 10.1 Taking Over of the Works and Sections 工程和分项工程的接收

　 10.2 Taking Over of Parts of the Works 部分工程的接收

　 10.3 Interference with Tests on Completion 对竣工试验的干扰

　 11 Defects Liability 缺陷责任

　 11.1 Completion of Outstanding Work and Remedying Defects 完成扫尾工作和修补缺陷

　 11.2 Cost of Remedying Defects 修补缺陷的费用

　 11.3 Extension of Defects Notification Period 缺陷通知期的延长

　 11.4 Failure to Remedy Defects 未能修补的缺陷

　 11.5 Removal of Defective Work 移出有缺陷的工程

　 11.6 Further Tests 进一步试验

　 11.7 Right of Access 进入权

　 11.8 Contractor to Search 承包商调查

　 11.9 Performance Certificate 履约证书

　 11.10 Unfulfilled Obligations 未履行的义务

　 11.11 Clearance of Site 现场清理

　 12 Tests after Completion 竣工后试验

　 12.1 Procedure for Tests after Completion 竣工后试验的程序

　 12.2 Delayed Tests 延误的试验

　 12.3 Retesting 重新试验

　 12.4 Failure to Pass Tests after Completion 未能通过的竣工后试验

　 13 Variations and Adjustments 变更和调整

　 13.1 Right to Vary 变更权

　13.2 Value Engineering 价值工程

　 13.3 Variation Procedure 变更程序

　 13.4 Payment in Applicable Currencies 以适用货币支付

　 13.5 Provisional Sums 暂列金额

　13.6 Daywork 计日工作

　 13.7 Adjustments for Changes in Legislation 因法律改变的调整

　 13.8 Adjustments for Changes in Cost 因成本改变的调整

　 14 Contract price and Payment 合同价格和支付

　 14.1 The Contract Price 合同价格

　 14.2 Advance payment 预付款

　 14.3 Application for Interim Payments 期中付款的申请

　 14.4 Schedule of Payments 付款价格表

　 14.5 Plant and Materials intended for the Works 拟用于工程的生产设备和材料

　 14.6 Interim Payments 期中付款

　 14.7 Timing of Payments 付款的时间安排

　 14.8 Delayed Payment 延误的付款

　 14.9 Payment of Retention Money 保留金支付

　14.10 Statement at Completion 施工报表

　 14.11 Application for Final Payment 最终付款的申请

　 14.12 Discharge 结清证明

　 14.13 Final Payment 最终付款

　 14.14 Cessation of Employer’s Liability 雇主责任的中止

　 14.15 Currencies of Payment 支付的货币

　 15 Termination by Employer 由雇主终止

　 15.1 Notice to Correct 通知改正

　 15.2 Termination by Employer 由雇主终止

　 15.3 Valuation at Date of Termination 终止日期时的估价

　 15.4 Payment after Termination 终止后的付款

　 15.5 Employer’s Entitlement to Termination 雇主终止的权利

　16 Suspension and termination by Contractor 由承包商暂停和终止

　 16.1 Contractor’s Entitlement to Suspend Work 承包商暂停工作的权利

　 16.2 Termination by Contractor 由承包商终止

　 16.3 Cessation of Work and Removal of Contractor’s Equipment 停止工作和承包商设备的撤离

　 16.4 Payment on Termination 终止时的付款

　 17 Risk and Responsibility 风险和职责

　 17.1 Indemnities 保障

　 17.2 Contractor’s Care of the Works 承包商对工程的照管

　17.3 Employer’s Risks 雇主的风险

　17.4 Consequence of Employer’s Risks 雇主风险的后果

　 17.5 Intellectual and Industrial Property Rights 知识产权和工业产权

　 17.6 Limitation of Liability 责任限度

　 18 Insurance 保险

　 18.1 General Requirements for Insurances 有关保险的一般要求

　 18.2 Insurance for Works and Contractor’s Equipment 工程和承包商设备的保险

　 18.3 Insurance against Injury to Persons and Damage to Property 人身伤害和财产损害险

　 18.4 Insurance for Contractor’s Personnel 承包商人员的保险

　19 Force Majeure 不可抗力

　 19.1 Definition of Force Majeure 不可抗力的定义

　 19.2 Notice of Force Majeure 不可抗力的通知

　19.3 Duty to Minimise Delay 将延误减至最小的义务

　 19.4 Consequences of Force Majeure 不可抗力的后果

　 19.5 Force Majeure Affecting Subcontractor 不可抗力影响分包商

　 19.6 Optional Termination, Payment and Release 自主选择终止、支付和解除

　100

　 19.7 Release from Performance under the Law 根据法律解除履约

　100

　 20 Claims, Disputes and Arbitration 索赔、争端和仲裁

　101

　 20.1 Contractor’s Claims 承包商的索赔

　101

　 20.2 Appointment of the Dispute Adjudication Board 争端裁决委员会的任命

　103

　 20.3 Failure to Agreement Dispute Adjudication Board 对争端裁决委员会未能取得一致时

　104

　 20.4 Obtaining Dispute Adjudication Board’s Decision 取得争端裁决委员会的决定

　105

　 20.5 Amicable Settlement 友好解决

　106

　 20.6 Arbitration 仲裁

　106

　20.7 Failure to Comply with Dispute Adjudication Board’s Decision 未能遵守争端裁决委员会的决定

　.......................................................................................... 107

　 20.8 Expiry of Dispute Adjudication Board’s Appointment 争端裁决委员会任命期满

　108

　1 General Provisions一般规定

　1.1 Definitions定义

　In the Conditions of Contract (“these Conditions”), which include Particular Conditions and these General Conditions, the following words and expressions shall have the meaning stated. Words indicating persons or parties include corporation and other legal entities, except where the context requires otherwise.

　在合同条件（“本条件”），包括专用条件和通用条件中，下列词语和措辞应具有以下所述的含义 .除上下文另有要求外，文中人员或当事各方等词语包括公司和其他合法实体.

　1.1.1 The Contract

　合同

　1.1.1.1

　“Contract” means the Contract Agreement, these Conditions, the Employer’s Requirement, the Tender, and further document (if any) which are listed in the Contract Agreement.

　“合同”系指合同协议书、本条件、雇主要求、投标书和合同协议书列出的其他文件（如果有）.

　1.1.1.2 “Contract Agreement” means the contract agreement referred to in Sub-Clause 1.6 [Contract Agreement], including any annexed memoranda.

　“合同协议书”系指第 1.6 款[合同协议书]中所述的合同协议书及所附各项备忘录.

　1.1.1.3 “Employer’s requirements” means the document entitled employer’s requirements, as included in the Contract, and any additions and modifications to such document in accordance with the Contract. Such document specifies the purpose, scope, and/or design and/or other technical criteria, for the Works.

　“雇主要求”系指合同中包括的，题为雇主要求的文件，其中列明工程的目标、范围、和（或）设计和（或）其他技术标准，以及按合同对此项文件所作的任何补充和修改.

　1.1.1.4 “Tender” means the Contractor’s signed offer for the Works and all other documents which the Contractor submitted therewith (other than these Conditions and Employer’s Requirements, if so submitted), as included in the Contract.

　“投标书”系指包含在合同中的由承包商提交的为完成工程签署的报价，以及随同提交的所有其他文件（本条件和雇主要求除外，如同时提交）.

　1.1.1.5 “Performance Guarantees” and “Schedule of payments” mean the documents so named (if any), as included in the Contract.

　“履约保证”和“付款计划表”系指合同中包括的具有上述名称的文件（如果有）.

　1.1.2 Parties and Persons各方和人员

　1.1.2.1 “Party” means the Employer or the Contractor, as the context requires. “当事方（或一方）”根据上下文需要，或指雇主，或指承包商。

　1.1.2.1 “Employer” means the person named as employer in the Contract Agreement and the legal successors in title to this person.

　“雇主”系指在合同协议书中被称为雇主的当事人及其财产所有权的合法继承人。

　1.1.2.3 “Contractor” means the person(s) named as contractor in the Contract Agreement and the legal successors in title to this person(s).

　“承包商”系指合同协议书中被称为承包商的当事人及其财产所有权的合法继承人。

　1.1.2.4 “Employer’s Representative” means the person named by the Employer in the Contract or appointed from time to time by the Employer under Sub-Clause 3.1 [ the Employe’r s Representative], who acts on behalf of the Employer.

　“雇主代表”系指由雇主在合同中指名的人员，或有时由雇主根据第 3.1 款［雇主代表的人员］的规定任命为其代表的人员。

　1.1.2.5 “Contractor’s Representative” means the person named by the Contractor in the Contract or appointed from time to time by the Contractor Sub-Clause 4.3 [the Contractor ’s Representative], who acts on behalf of the Contractor.

　“承包商代表”系指由承包商在合同中指名的人员，或有时由承包商根据第 4.3 款[承包商代表]的规定任命为其代表的人员。

　1.1.2.6 “Employer’s Personnel” means the Employer ’s Representative, the assistants referred to in Sub-Clause 3.2 [Other Employer’s Personnel] and all other staff, labour and other employees of the Employer and of the Employer’s Representative; and any other personnel notified to the Contractor, by the Employer or the Employe’r s Representative, as Employer’s Personnel.

　“雇主人员”系指雇主代表、第 3.2 款[其他雇主人员]中提到的助手、以及雇主和雇主代表的所有其他职员、工人和其他雇员，以及雇主或雇主代表通知承包商作为雇主人员的任何其他人员。

　1.1.2.7

　“Contractor’s Personnel” means the Contractor’s Representative and all personnel whom the Contractor utilizes on Site, who may include the staff, labour and other employees of the Contractor and of each Subcontractor, and any other personnel assisting the Contractor in the execution of the works.

　“承包商人员”系指承包商代表和承包商在现场聘用的所有人员，包括承包商和每个分包商的职员、工人和其他雇员，以及所有其他帮助承包商实施工程的人员。

　1.1.2.8 “Subcontractor” means any person named in the Contract as a subcontractor, or any person appointed as a subcontractor, for a part of the Works; and the legal successors in title to each of these persons.

　“分包商”系指为完成部分工程，在合同中指名为分包商、或被任命为分包商的任何人员，以及这些人员财产所有权的合法继承人。

　1.1.2.9 “DAB” means the person or three persons so named in the Contract, or other person(s) appointed under Sub-Clause 20.2 [Appointment of the Dispute Adjudication Board] or Sub-Clause

　20.3 [Failure to Agree Dispute Adjudication Board].

　“DAB（争端裁决委员会）”系指在合同中如此指名的一名或三名人员，或根据第 20.2 款[争端裁决委

　员会的任命]或第 20.3 款[对争端裁决委员会未能取得一致]的规定任命的其他人员。

　1.1.2.10 “FIDIC” means the Federation International des Ingenieurs-Conseils, the international federation of consulting engineers.

　“菲迪克（FIDIC）”系指国际咨询工程师联合会。

　1.1.3 Dates ,Test, Periods and Completion日期、试验、期限和竣工

　1.1.3.1 “Base Date” means the date28 days prior tothe latest date for submission of the Tender.

　“基准日期”系指递交投标书截止前 28 天的日期。

　1.1.3.2 “Commencement Date” means the date notified under Sub-Clause 8.1 [Commencement of Works], unless otherwise defined in the Contract Agreement.

　“开工日期”系指根据第 8.1 款[工程的开工]的规定通知的日期，合同协议书中另有规定的除外。

　1.1.3.3 “Time for Completion” means the time for completing the Works or a Section (as the case may be) under Sub-Clause 8.2 [Time for Completion], as stated in the Particular Conditions (with any extension under Sub-Clause 8.4 [Execution of Time for Completion]), calculated from the Commencement Date.

　“竣工时间”系指专用条件中规定的，自开工日期算起，至工程或某分项工程（视情况而定）根据第

　8.2 款[竣工时间]规定的要求竣工（连同根据第 8.4 款[竣工时间的延长]的规定提出的任何延长期）的全部时间。

　1.1.3.4 “Tests on Completion” means the tests which are specified in the Contract or agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the works or a Section (as the casemay be) are taken over by the Employer.

　“竣工试验”系指在合同中规定或双方商定的，或按指示作为一项变更的，在工程或某分项工程（视情况而定）被雇主接收前，根据第 9 条[竣工试验]的要求，进行的试验。

　1.1.3.5 “Taking-Over Certificate” means a certificate issued under Clause 10 [Employer’s Taking Over].

　“接收证书”系指根据第 10 条[雇主接收]的规定颁发的证书。

　1.1.3.6 “Tests after Completion” means the tests (if any) are specified in the Contract and which are carried out under Clause 12 [Tests after Completion] after the works or a Section (as the case may be) are taken over by the Employer.

　“竣工后试验”系指在合同中规定的，在工程或某分项工程（视情况而定）被雇主接收后，根据第 12条[竣工后试验]的要求，进行的试验（如果有）。

　1.1.3.7 “Defects Notification Period” means the period for notifying defects in the Works or a Section (as the case may be) under Sub-Clause 11.1 [Completion of Understanding Works and Remedying Defects], as stated in the Particular Conditions (with any extension under Sub-Clause

　11.3 [Extension of Defects Notification Period]), calculated from the date on which the Works or Section is competed as certified under Sub-Clause 10.1 [Taking Over of the Works and Sections]. If no such period is stated in the Particular Conditions, the period shall be one year.

　“缺陷通知期限”系指专用条件中规定的，自工程或某分项工程（视情况而定）根据第 10.1 款[工程

　和分项工程的接收]的规定证明的竣工日期算起，至根据第 11.1 款[完成扫尾工作和修补缺陷]的规定通知

　工程或分项工程存在缺陷的期限（连同根据第 11.3 款[缺陷通知期限的延长]的规定提出的任何延长期）。如果专用条件中没有提出这一期限，该期限应为一年。

　1.1.3.8 “Performance Certificate” means the certificate issued under Sub-Clause 11.9 [Performance Certificate].

　“履约证书”系指根据第 11.9 款[履约证书]的规定颁发的证书。

　1.1.3.9 “day” means a calendar day and “year” means 365 days. “日（天）”系指一个日历日，“年”系指 365 天。

　1.1.4 Money and Payments款项与付款

　1.1.4.1 “Contract Price” means the agreed amount stated in the Contract Agreement for the design, execution and completion of the Works and the remedying of any defects, and includes adjustment (if any) in accordance with the contract.

　“合同价格”系指在合同协议书中写明的、经商定的工程设计、施工、竣工和缺陷修补的款额，包括以及按照合同做出的调整（如果有）。

　1.1.4.2 “Cost” means all expenditure reasonably incurred (or to be incurred) by the Contractor, whether on or off the Site, including overhead and similar charges, but does not include profit.

　“成本（费用）”系指承包商在现场内外所发生（或将发生）的所有合理开支，包括管理费用及类似的支出，但不包括利润。

　1.1.4.3 “Final Statement” means the statement defined in Sub-Clause 14.11[Application for Final Payment].

　“最终报表”系指第 14.11 款[最终付款的申请]规定的报表。

　1.1.4.4 “Foreign Currency” means a currency in which part (or all) of the Contract Price is payable, but not the Local Currency.

　“外币”系指可用于支付合同价格中部分（或全部）款项的当地货币以外的某种货币。

　1.1.4.5 “Local Currency” means the currency of the Country. “当地货币”系指工程所在国的货币。

　1.1.4.6 “Provisional Sum” means a sum (if any) which is specified in the Contract as a provisional sum, for the execution of any part of the Works or for the supply of Plant, Material or services under Sub-Clause 13.5 [Provisional Sums].

　“暂列金额”系指合同中规定作为暂列金额的一笔款额（如果有），根据第 13.5 款[暂列金额]的规定，用于工程某一部分的实施，或用于提供生产设备、材料或服务。

　1.1.4.7 “Retention Money” means the accumulated retention moneys which the Employer retains under Sub-Clause 14.3 [Application for Interim Payments] and pays under Sub-Clause 14.9 [Payment of Retention Money].

　“保留金”系指雇主根据第 14.3 款[期中付款的申请]的规定扣留的保留金累计金额，根据第 14.9 款[保留金的支付]的规定进行支付。

　1.1.4.8 “Statement” means a statement submitted by the Contractor as part of an application for payment under Clause 14 [Contract Price and Payment].

　“报表”系指承包商根据第 14 条[合同价格和付款]的规定提交的作为付款申请的组成部分的报表。

　1.1.5 Works and Goods工程和货物

　1.1.5.1 “Contractor’s Equipment” means all apparatus, machinery, vehicles and other things required for the execution and completion of the Works and remedying of any defects. However, Contractor’s Equipment excludes Temporary Works, Employer’s Equipment (if any), Plant, Materials and any other things intended to form or forming part of the Permanent Works.

　“承包商设备”系指为实施和完成工程、以及修补任何缺陷需要的所有仪器、机械、车辆和其他物品。但承包商设备不包括临时工程、雇主设备（如果有）、以及拟构成或正构成永久工程一部分的生产设备、材料和其他任何物品。

　1.1.5.2 “Goods” means Contractor’s Equipment, Materials, Plant and Temporary Works, or any of them as appropriate.

　“货物”系指承包商设备、材料、生产设备和临时工程，或视情况其中任何一种。

　1.1.5.3 “Materials” means things of all kinds (other than Plant) intended to form or forming part of the Permanent Works,including the supply-only materials (if any) to be supplied by the Contractor under the Contract.

　“材料”系指拟构成或正构成永久工程一部分的各类物品（生产设备除外），包括根据合同要由承包商供应的只供材料（如果有）。

　1.1.5.4 “Permanent Works” means the permanent works to be designed and executed by the Contractor under the Contract.

　“永久工程”系指根据合同承包商要进行设计和施工的永久性工程。

　1.1.5.5 “Plant “means the apparatus, machinery and vehicles intended to form or forming part of the Permanent Works.

　“生产设备”系指拟构成或正构成永久工程一部分的仪器、机械和车辆。

　1.1.5.6 “Section” means a part of the Works specified in the Particular Conditions as a Section (if any).

　“分项工程”系指在专用条件中确定为分项工程（如果有）的工程组成部分。

　1.1.5.7 “Temporary Works” means all temporary works of every kind (other than Contractor’s Equipment) required on Site for the execution and completion of the Permanent Works and the remedying of any defects.

　“临时工程”系指为实施和完成永久工程及修补任何缺陷，在现场所需的所有各类临时性工程（承包商设备除外）。

　1.1.5.8 “Works” means the Permanent Works and the Temporary Works, or either of them as appropriate.

　“工程”系指永久工程和临时工程，或视情况指二者之一。

　1.1.6 Other Definitions其他定义

　1.1.6.1 “Contractor’s Documents” means the calculations, computer programs and other software, drawings, manuals, models and other documents of a technical nature supplied by the Contractor under the Contract; as described in Sub-Clause 5.2 [Contractor’s Documents].

　“承包商文件”系指第5.2 条款[承包商文件]中所述的，承包商根据合同应提交的所有计算书、计算机程序和其他软件、图纸、手册、模型、以及其他技术性文件。

　1.1.6.2 “Country” means the country in which the Site (or most of it) is located, where the Permanent Works are to be executed.

　“工程所在国”系指实施永久工程的现场（或其大部分）所在的国家。

　1.1.6.3 “Employer’s Equipment” means the apparatus, machinery and vehicles (if any) made available by the Employer for the use of the Contractor in the execution of the Works, as stated in the Employer’s Requirements; but does not include Plant which has not been taken over by the Employer.

　“雇主设备”系指雇主要求中所述的，由雇主提供的供承包商在实施工程中使用的仪器、机械和车辆

　（如果有），但不包括尚未经雇主接收的生产设备。

　1.1.6.4 “Fore Majeure” is defined in Clause 19 [Fore Majeure]. “不可抗力”见第 19 条[不可抗力]的定义。

　1.1.6.5 “Laws” means all national (or state) legislation, statutes, ordinances and other laws, and regulations and by-laws of any legally constituted public authority.

　“法律”系指所有全国性（或洲的）法律、条例、法

Tags：中英文对照条件施工

首页 > 演讲致辞 > 会议致辞 / 正文

FIDIC设计采购施工(EPC)合同条件(中英文对照版)_文档

猜你喜欢